STOCKER INTERIORS LIMITED
Registered Office: 76 Harwood Lane, Clifton, Shefford, England, SG17 5NW
Company Number: 16528926
Terms & Conditions
These Terms & Conditions govern the use of this website and the engagement of services provided by Stocker Interiors Limited. By using this website or engaging the company for services, you agree to be bound by these terms. If you do not agree, you should not use the website or proceed with services.
1. Definitions
“Company” refers to Stocker Interiors Limited.
“Client” refers to any individual or organisation enquiring about or purchasing services.
“Services” refers to interior design, specification, planning, and related consultancy work.
“Website” refers to all pages and content published under the company’s web domain.
2. Scope of Website Information
All website content is provided for general information only. It is not intended to form contractual terms or professional advice. Service descriptions are indicative and may be adapted to suit specific project requirements. The company reserves the right to modify website content at any time without notice.
3. Service Engagement
No services are supplied until confirmed through a written agreement, proposal, or contract issued by the company and accepted by the client. Scope, deliverables, timelines, and fees will be defined in writing. Any work requested outside the agreed scope may be subject to additional fees and revised timelines.
4. Client Responsibilities
Clients agree to provide accurate, complete, and timely information relevant to the project. This includes measurements, drawings, access details, approvals, and preferences where required. The company is not responsible for errors arising from inaccurate or incomplete information supplied by the client or third parties.
Clients are responsible for obtaining any necessary permissions, landlord approvals, planning consents, or building regulation approvals unless expressly agreed otherwise in writing.
5. Fees and Payment
Fees will be set out in a written proposal or agreement. Unless otherwise stated, invoices are payable within the stated payment term. The company reserves the right to pause or withhold work where payments are overdue. Deposits or staged payments may be required before work begins or continues.
All fees are exclusive of third-party costs unless explicitly stated. Third-party goods and contractor costs are normally contracted directly by the client.
6. Variations and Changes
Design development is an iterative process. Reasonable revisions may be included where stated in the service agreement. Significant changes to the brief, scope, or direction may result in additional charges and revised delivery dates. All variations should be agreed in writing.
7. Third-Party Suppliers and Contractors
The company may recommend suppliers, products, or contractors, but does not warrant their performance or contractual behaviour. Any contract for goods or construction services is between the client and the third party. The company is not liable for third-party delays, defects, pricing, or availability.
8. Intellectual Property
All original drawings, concepts, specifications, schedules, and design materials produced by the company remain its intellectual property unless otherwise agreed in writing. Upon full payment, the client is granted a non-exclusive licence to use the materials for the specific project only.
Design materials may not be reused, resold, or transferred to other projects without written permission.
9. Limitations of Liability
To the fullest extent permitted by law, the company shall not be liable for indirect, consequential, or economic losses arising from use of the website or services. Liability for direct loss relating to services shall not exceed the total fees paid for those services.
The company is not responsible for construction outcomes, installation quality, or product performance where it is not the installer or supplier.
10. Timelines and Delays
Any timelines provided are estimates unless expressly stated as fixed deadlines. Delivery may be affected by client response times, third-party inputs, and product availability. The company is not liable for delays outside its reasonable control.
11. Confidentiality
The company will treat client project information as confidential and will not disclose it to unrelated third parties except where required for service delivery or by law. The company may reference project types in general terms for portfolio purposes unless the client requests otherwise in writing.
12. Website Use
Users agree not to misuse the website, attempt unauthorised access, introduce malicious code, or use the content for unlawful purposes. The company may restrict access where misuse is suspected.
13. Data Protection
Personal data is handled in accordance with the company’s Privacy Policy. By submitting information through the website or by email, users consent to reasonable processing for enquiry handling and service delivery.
14. Termination
The company may terminate or suspend a service agreement where there is non-payment, repeated failure to provide required information, or abusive conduct. Clients may terminate in accordance with the terms set out in their service agreement. Fees for work already completed remain payable.
15. Governing Law
These Terms & Conditions are governed by the laws of England and Wales. Any disputes shall be subject to the jurisdiction of the courts of England and Wales.
16. Updates
These Terms & Conditions may be updated from time to time. The latest version published on the website applies to current use and future engagements unless otherwise agreed in writing.